Glovers Fencing
Pty Ltd.
Terms & Conditions
Introduction
These Terms and Conditions govern your use of the Glovers Fencing Pty Ltd website and the supply and installation services provided by Glovers Fencing Pty Ltd (“the Company”, “we”, “us”, or “our”). By accessing or using this website or engaging our services, you agree to be bound by these Terms and Conditions in full.
Services
Glovers Fencing Pty Ltd specialises in the supply and installation of fencing products including Colorbond, aluminium and timber fencing. All quotes provided by Glovers Fencing Pty Ltd are estimates based on the information supplied by the client and are subject to a site inspection before final confirmation.
Quotes and Pricing
All quotes from Glovers Fencing Pty Ltd are valid for 60 days from the date of issue unless otherwise specified in writing.
Prices may be subject to change due to variations in material costs, labour rates, or unforeseen site conditions beyond our control.
A deposit is required to secure your booking, with the balance payable upon completion or as per the payment terms outlined in the invoice.
Responsibility for Payment
Upon acceptance of a quotation, payment responsibility rests with the person or legal entity to whom the quotation is addressed ("the Purchaser").
Acceptance authorises Glovers Fencing Pty Ltd to proceed with all agreed works, including demolition of existing fences or structures if applicable.
The Purchaser confirms that all necessary approvals from property owners, occupants, and authorities have been obtained.
Any delays caused by failure to obtain approvals may incur additional costs payable by the Purchaser.
Payment Terms
Payments must be made according to the schedule detailed in the invoice or contract.
Glovers Fencing Pty Ltd may issue progress claims based on work completed at its discretion. Such claims are payable upon receipt of invoice.
Late payments may result in suspension of work until payment is received.
Final payment is due upon completion of the works.
Any disputes or concerns must be submitted in writing within 7 days of completion before further action.
Glovers Fencing Pty Ltd reserves the right to withhold delivery or services until payment obligations are fulfilled and will legally pursue unpaid invoices.
The Purchaser agrees to pay all costs incurred by Glovers Fencing Pty Ltd in recovering unpaid amounts, including legal and debt recovery fees, on an indemnity basis.
Ownership and Risk
Title to goods supplied remains with Glovers Fencing Pty Ltd until full payment of all amounts due, including collection and legal costs, is received.
Risk passes to the Purchaser upon delivery.
If payment defaults occur, Glovers Fencing Pty Ltd or its agents may enter the premises without notice to repossess goods, including installed materials.
The Purchaser must provide reasonable access.
Removal may leave visible evidence which will not be repaired by the Company.
The Purchaser is responsible for all costs incurred in repossession actions. Entry for repossession will not constitute trespass or similar action against Glovers Fencing Pty Ltd or its agents.
Site Access and Conditions
The client is responsible for ensuring that Glovers Fencing Pty Ltd has safe and legal access to the work site.
Any delays, additional costs, or complications arising from restricted site access or unforeseen site conditions will be the responsibility of the client.
The client must inform Glovers Fencing Pty Ltd of any underground services, easements, or site hazards prior to commencement of work.
Liability and Insurance
Glovers Fencing Pty Ltd holds all necessary licenses and insurance coverage required by law, including Public Liability Insurance.
We are not liable for delays or damages caused by factors outside our control, such as adverse weather, acts of third parties, or changes in council regulations.
Clients are responsible for obtaining any required permits or approvals from relevant authorities.
Warranty
Glovers Fencing Pty Ltd provides warranties on materials and workmanship as outlined in the contract and as per manufacturer guidelines.
The warranty does not cover damage caused by normal wear and tear, misuse, vandalism, or external factors beyond our control.
Any claims under warranty must be made in writing and within the warranty period.
Intellectual Property
All content on the Glovers Fencing Pty Ltd website, including text, images, logos, and designs, is the intellectual property of Glovers Fencing Pty Ltd and is protected by copyright law.
No content may be copied, reproduced, or used without prior written permission from Glovers Fencing Pty Ltd.
Privacy
Glovers Fencing Pty Ltd is committed to protecting your privacy and handling your personal information in accordance with our Privacy Policy.
Personal data collected through this website or during the course of our services will be used solely for the purposes of providing and managing our fencing services.
Changes to Terms
Glovers Fencing Pty Ltd reserves the right to update or modify these Terms and Conditions at any time without prior notice.
Continued use of our website or services after such changes constitutes acceptance of the updated terms.
Governing Law
These Terms and Conditions are governed by and construed in accordance with the laws of New South Wales, Australia.
Any disputes arising out of or in connection with these Terms shall be subject to the exclusive jurisdiction of the courts of New South Wales.
Currency
All financial transactions are conducted in Australian Dollars (AUD) only.